Newspaper Page Text
Legal Advertising
I notice to contractors
FEDERAL aid project
NO. F 085-1 (2)
COUNTY OF BRANTLEY
I Sealed proposals will be re
-4 ive d by the State Highway De-
I nartment of Georgia at the Gen-
I e--al Office no - 2 Ca P itol S( l ua re,
I Atlanta, Ga., until 11 A. M. East
fl ern Standard time, July 27, 1956,
I and publicly opened for furnish
fl ing a n labor, material, equipment
I and other things necessary for the
I construction of 3.516 miles of
■ grading for two additional traffic
| lanes located in Brantley County
I on what is locally known as the
I Nahunta-Jesup road, State Route
I 23, U. S. Route 301. Beginning at
I a point approximately five miles
I nO rth of Nahunta and extending
I nor th, parallel to the present
road. Otherwise known as Federal
I Aid Project F-085-1 (2) in Brant
| ley County. The work will be let
■ in one contract.
I THE APPROXIMATE
I QUANTITIES are as
FOLLOWS
I 102.592 Acres - Clearing and
I Grubbing-Lump Sum
I 66.195 Acres - Random Clearing
| and Grubbing - Per Acre.
I 686273 Cu. Yds. Unclassified
I Excavation and Borrow, Includ
| ing ditches and including material
I 1131379 Cu. Yds. One-half mile
I Overhaul on Excavation
I 40 Cu. Yds. - Excavation for
I Culverts and minor structures.
I 2.49 Cu. Yds. - Class “B” Con-
I crete Headwalls.
i 400 Lin. Ft. 12” Pipe SD.
j 30 Lin. Ft. 15” Pipe SD
f 70 Lin. Ft. 18” Pipe SD
f 35 Lin. Ft. 18” Concrete Pipe
I SD Ext.
1427 Lin. Ft. 15” Pipe CD.
s 50 Lin. Ft. 18” Pipe CD
68 Lin. Ft. 30” Pipe CD
7 Lin. Ft. 30” Concrete Pipe
j CD Ext.
1000 Lin. Ft. 6” Perforated Pipe
j underdrain
695 Lin. Ft. Culvert Pipe Re
moved, SD or CD.
135 Lin. Ft. Culvert Pipe Re
| laid, SD or CD.
I 19.5 Sq. Yds. Plain Sand Ce
ment Bag Rip Rap.
90 Each Concrete R-W Markers
2 Each Posts for FAP Markers
2 Each Arrows for FAP Mark
ers.
2 Each Plates for FAP Markers
120000 Sq. Yds. Sprigging Slop
es and Medians.
420 Sq. Yds. Loose Sod Rip Rap
for Side Drains.
120.4 M. Gals. Water for Gras
sing.
9.95 Tons. First Application
Fertilizer.
1 3483 Lbs. Second Application
Fertilizer.
2 Each. Remove Conrete Right
of Way Markers.
2 Each. Reset Concrete Right
of Way Markers.
2890 Sq. Yds. Remove & Stock
pile Sand Cement Block Rip Rap.
2023 Sq. Yds. Reset Sand Ce
ment Block Rip Rap from Stock
l pile.
* 5935 Sq. Yds. Sand Cement
Block Rip Rap.
16 Each. Drop Inlets, Concrete,
Std. 1019 or Brick, Std. 1019-A,
Type “B” Mod. for 4” Weir, H-4’
or Less.
1 Each. Drop Inlet, Concrete,
Std. 1019 or Brick, Std. 1019-A,
Type “C”, H-4’ or Less.
1 Each. Drop Inlet, Concrete,
Std. 1019, or Brick, Std. 1019-A,
Type “E” with Hood, H-4’ or less.
2 Lin. Ft. Additional Depth
Drop Inlets, Type “C”.
2180 Cu. Yds. Selected Material
Surfacing for County Road,
Drives and Interchanges, Includ
ing Material.
16.224 MBM. Bridge Timber-
Treated 12 Lbs. Spur Dikes.
2603 Lin. Ft. Timber Piling-
Treated 16 Lbs. Spur Dikes.
Said work shall begin within
' ten (10) days after formal exe
cution of contract and shall be
completed within 240 working
days. When contract has been ex
ecuted, written notice shall be
give the Contractor, at which
time, and not before, work may
be started.
Contract executed pursuant to
this Notice is binding on the
State Highway Department, as
s uch. Said contract will not create
liability, expressed or implied,
against the undersigned Chair
man of the State Highway Board,
as an individual nor against any
employee of the State Highway
Department, in his or her individ
ual capacity.
The minimum wage to be paid
Un der this contract shall be the
amounts set out in the Labor
Provisions included in the Propo
sal The attention of bidders is
1 ceded to the Special Provisions
covering employment of labor,
methods of construction, sublet
lng or assigning the contract and
' 3 the use of domestic materials.
Plans and specifications are on
1 e at the office of the under-
Sl §ned at Atlanta, and at Savan
oah, Georgia, and at the office of
e Board of County Commis
^mners of Brantley County at Na-
hunta, Georgia, where they may
be inspected free of charge. Cop
ies of the plans may be obtained
upon payment in advance of the
sum of $13.00. Copies of the Gen
eral Specifications may be ob
tained upon payment in advance
of the sum of $3.00, which sums
will not be refunded.
Proposals must be submitted on
regular forms, which will be sup
plied by the undersigned, and
may be obtained by a payment, in
advance of $5.00 for each pro
posal issued. When the proposal is
submitted, it must be accompan
ied by a certified check, cashier’s
check, negotiatable United States
Bonds, or other acceptable secur
ity ^n the amount of $3000.00, and
must be plainly marked “Proposal
for Road Construction,” County
and Number, and show the time
of opening as advertised. Check
of the low bidder will be cashed
and all other checks will be re
turned as soon as the contract is
awarded, unless it is deemed ad
visable by the State Highway De
partment to hold one or more
checks. If an unusual condition
arises, the State Highway Depart
ment reserves the right to cash
all checks. Bidders Bond will not
be accepted. Bond will be re
quired of the successful bidder as
required by law.
Contracts will not be awarded
to contractors who have not been
placed on the list of qualified
Contractors prior to the date of
award. No proposal will be issued
to any bidder later than 9 AM
Eastern Standard Time of the
date of opening bids.
All bids must show totals for
each item and total amount of
bid. Right is reserved in the un
dersigned to delay the award of
the contract for a period not to
exceed thirty (30) days from the
date of opening bids, during
which period bids shall remain
open and not subject to with
drawal. Right is also reserved in
the undersigned to reject any and
all bids and to waive all form
alities.
Upon compliance with the re
quirements of the Standard Spec
ifications, Ninety (90) per cent of
the amount of work done in any
calendar month will be paid for
by the 25th. day of the succeed
ing month, providing that pay
rolls have been submitted as re
quired and the remainder within
thirty (30) days after the Final
Statement is approved by the En
gineer.
This the 9th day of July, 1956.
STATE HIGHWAY
DEPARTMENT
OF GEORGIA
W. A. BLASINGAME
Chairman
NOTICE TO CONTRACTORS
GEORGIA RURAL ROADS
AUTHORITY PROJECT
NO. RR-PR 43 (1) & SPUR
COUNTY OF BRANTLEY
Sealed proposals will be rece
ived by the Georgia Rural Roads
Authority at its General Office at
No. 2 Capitol Square, Atlanta,
Georgia, until 11. a. m., Eastern
Standard Time, July 27, 1956, for
furnishing all labor, material,
equipment and other things neces
sary for contruction of 5.505 miles
of grading and paving and one
bridge on the Nahunta-Oak Grove
Church-Raybon Road, beginning
at State Route 23 near Raybon
School, and extending west via
Oak Grove Church, thence south
toward Nahunta, including 1300
foot spur west from intersection
at Oak Grove Church.
Plans and Specifications are on
file at the office of the under
signed at Atlanta, and at the
office of the State Highway De
partment, No. 2 Capitol Square,
Atlanta, Georgia, and at the office
of the Division Engineer of the
State Highway Department at
Savannah, Georgia, and at the of
fice of the Board of County Com
missioners of Brantley County at
Nahunta, Georgia, where they
may be inspected free of charge.
No Plans will be furnished for
sale to prospective bidders.
Copies of the Standard Speci
fications may be obtained upon
payment in advance of the sum of
$3.00, which sum will not be re
funded.
The Standard Specifications of
the State Highway Department
of Georgia have been adopted
by the Georgia Rural Roads Auth
ority and will govern any con
struction under these proposals.
The work will be let in one con
tract.
THE APPROXIMATE QUAN
TITIES FOR ROADWAY ARE
AS FOLLOWS
53.684 Acres Clearing & Grub
bing, Lump Sum
15.000 Acres Random Clearing
& Grubbing, Per Acre
60000 Cu. Yds. Unclassified Ex
cavation & Borrow, Including
Ditches and Shoulders
5.488 Miles Grading per Mile
300000 Sta. Yds. Overhaul on
Excavation
5.497 Miles Special Subgrade
Compaction •
693 Cu. Yds. Excavation for
Culverts & Minor Structures
100 Cu. Yds. Selected Material
Backfill, Culvert Foundations
465.41 Cu. Yds. Class “A” Con
crete Culverts
36574 Lbs. Bar Reinforcing
Steel
630 Lin. Ft. 18” Pipe SD
105 Lin. Ft. 24” Pipe SD
300 Lin. Ft. 18” Pipe CD
180 Lin. Ft. 24” Pipe CD
45 Lin. Ft. 30” Pipe CD
231 Lin. Ft. Culvert Pipe Re
moved, SD or CD
84 Lin. Ft. Culvert Pipe Re
laid, SD or CD
40 Cu. Yds. Sand Cement End
walls
60000 Sq. Yds. Sprigging Slopes
& Shoulders
300 Sq. Yds. Loose Sod Rip Rap
100 Sq. Yds. Sod Ditch Checks
60 M .Gals. Water for Grassing
5 Tons First Applications Ferti
lizer
1748 Lbs. Second Application
Fertilizer
61450 Sq. Yds. 6” Sand Bitumi
nous Roadmix
185000 Gals Cutback Asphalt
for Roadmix
18500 Gals. Cutback Asphalt
Seal i
61450 Sq: Yds. Single Surface
Treatment, Type 1
61450 Sq. Yds. Liquid Seal
LUMP SUM Remove Existing
Bridge, Sta. 122-1-28
LUMP SUM Remove Existing
Bridge, Sta. 123+88
LUMP SUM Remove Existing
Bridge, Sta. 141 +35
LUMP SUM Remove Existing
Bridge, Sta. 148 +O4
106.7 Sq. Yds. Reinforced Con
crete Approach Slabs
4 Each Concrete Drop Inlet
Spillways, Std. 9017, Type “A”
1 Grate
60 Lin. Ft. 8” Corr. Metal Pipe
Slope Drain
60 Lin. Ft. 9” x 16” Concrete
Header with Raised Edge
200 Lin. Ft. Guard Rail
30 Sq. Yds. 6” Bituminous
Bound Base, RR Crossing
2 Each Reflectorized RR Cross
ing Warning Signs, Type “F”
2 Each Reflectorized RR Cross
ing Stop Signs, Type “F”
2 Each Reflectorized RR Cross
Buck Signs, Type “E”
APPROXIMATE QUANTITIES
FOR THE BRIDGE ARE
AS FOLLOWS
35.38 Cu. Yds. Class “A” Con
crete
97.12 Cu. Yds. Class “AA” Con
crete
48393 Lbs. Bar Reinforcing
Steel
2 Each Timber Test Piles
1800 Lin. Ft. Timber Piling,
Treated 16 Lbs.
LUMP SUM Remove Existing
Bridge, Sta. 303+63
300 Sq. Yds. Sand Cement Rip
Rap
OR
150 Tons Plain Stone Rip Rap
Said work shall begin within
ten (10) days after formal exe
cution of contract and shall be
completed within 240 working
days. When contract has been
executed, written notice shall
be given the Contractor, at which
time, and not before, work may
be started.
Contract executed pursuant to
this Notice is binding on the
Georgia Rural Roads Authority
as such. Said contract will not
create liability, expressed or im
plied, against the undersigned
Chairman of the Georgia Rural
Roads Authority as an individual,
nor against any employee of the
Georgia Rural Roads Authority in
his or her individual capacity
nor against the State Highway
Department of Georgia, nor
against any officer or employee
of the State Highway Department
in his or her individual capacity.
Proposals must be submitted on
regular forms which will be sup
plied by the undersigned’, and
must be accompanied b? a certi
fied check, cashier’s check, nego
tiable United States Bonds or
other acceptable security in the
amount of $2500.00, and must be
plainly marked “Proposal for
Road Construction”, County and
Number, and show the time of
opening as advertised. Check of
the low bidder will be cashed
and all other checks will be re
turned as soon as the contract is
awarded, unless it is deemed ad
visable by the Authority to hold
one or more checks. If an unus
ual condition arises, the Authori
ty reserves the right to cash all
checks. Bidders Bond will not be
accepted.
A charge of $5.00 will be made
for each proposal issued.
Such a bond will be required
of the successful bidder as re
quired by law for contractors
contracting with the State High
way Department of Georgia.
Contracts will not be awarded
to contractors who have not been
placed on the list of qualified
contractors prior to the date of
award. No prosposals will be
issued to any bidder later than
9 A. M. Eastern Standard Time
of the date of opening bids.
All bids must show totals for
each item and total of amount
of bid. Right is reserved to
delay the award of the contract
for a period of not to' exceed thir
ty (30) days from the date of
opening bids, during which period
bids shall remain open and not
subject to withdrawal. Right is
reserved to reject any and all bids
and to waive all formalities.
Upon compliance with the re
quirements of the standard speci
fications, ninety (90) percent of
the amount of work done in any
calendar month will be paid for
by the 25th day of the succeed
ing month, and the remainder
within thirty (30) days after
final estimate is approved by the
Engineer.
This the 6 day of July 1956.
GEORGIA RURAL
ROADS AUTHORITY
ROGER H. LAWSON
CHAIRMAN
GEORGIA, BRANTLEY
COUNTY
TO THE SUPERIOR COURT
OF SAID COUNTY:
The Petition of R. R. Kelly, H.
H. Colvin, Ira Thomas, J. E.
Thomas, L. C. Colvin, Olin Du-
Bose, C. E. Crews, J. F. Larkins,
G. R. Stone, Fred Dowling, S. B.
Kelly, all of Hoboken, Georgia,
respectfully shows:
1. Petitioners desire for them
selves, their associates and suc
cessors to be incorporated under
the name and style of “HOBO
KEN MISSIONARY BAPTIST
CHURCH, INC.”, for a period of
Thirty-five (35) years.
2. Said corporation shall func
tion as a church institution of
the Missionary Baptist Faith, in
dependent of but cooperating
with the Southern Baptist Con
vention and Georgia Baptist Con
vention, and is not organized and
shall not be operated for pecun
iary gain and profit, and shall
have no capital stock.
3. The principal office of said
corporation shall be in Brantley
County, Georgia.
4. Petitioners desire that the
by-laws of said corporation shall
be adopted by its members, and
such by-laws shall provide for
membership, the officers of the
church, the manner of their se
lection, and such other rules as
may appropriate to the conduct
and management of the affairs of
the church, including provisions
whereby the by-laws may be a
mended.
5. Your petitioners exhibit
herewith a certificate of the Sec
retary of State of the State of
Georgia as required by Section
22-1803, Georgia Code Annotated.
WHEREFORE, your petitioners
pray to be incorporated under the
name and style aforesaid with all
the rights, powers, privileges and
immunities herein set forth, and
as may be necessary, proper, or
incidental to the purposes here
of, and as may inherent in or al
lowed to like corporations under
the laws of this State as they
now exist or may hereafter exist.
By BLOUNT & GIBSON
Attorneys for Petitioners
GEORGIA, BRANTLEY
COUNTY
The foregoing petition of R. R.
Kelly, H. H. Colvin, Ira Thomas,
J. E. Thomas, L. C. Colvin, Olin
Dubose, C. E. Crews, J. F. Lar
kins, G. R. Stone, Fred Dowling,
S. B. Kelly, for a charter having
been read on considered; and it
appearing to the Court that said
petition is within the purview
and intent of the law in such
cases made and provided, and it
further appearing to the Court
that petitioners have complied
with all conditions precedent and
all statutory requirements appli
cable to such petitions:
IT IS HEREBY ORDERED
AND ADJUDGED, that said peti
tion be, and the same is hereby,
granted, and the petitioners and
their successors are hereby in
corporated for the term of thirty
five (35) years, with the right of
renewal as may be now or here
after provided by law, as a body
corporate under the name and
style of “HOBOKEN MISSION
ARY BAPTIST CHURCH, Inc.
“without capital stock, and with
all of the powers, privileges and
immunities set forth in said peti
tion, together with such other
rights, powers, privileges and im
munities as are or may hereafter
be afforded by the laws of this
State to similiar corporations.
This 3rd day of July, 1956.
CECIL RODDENBERRY,
Judge of the Superior
Court of Brantley County
Georgia.
8-9
Notice is hereby given that
the partnership heretofore sub
sisting between us, the under
signed, Mrs. F. A. Lewis (Mrs.
Addie Lewis) and R. C. Harrell,
Jr., heretofore carrying on busi
ness as partners in Brantley
County, Georgia, under the
style and firm name of Lewis
& Harrell, having been dissolv
ed by mutual consent as and
from the 30th day of June, 1956.
This the 2nd day of July, 1956
Mrs. Addie L. Lewis
R. C. Harreli, Jr. B|9
GEORGIA, BRANTLEY
COUNTY.
WHEREAS, heretofore,' on De
rember 16, 1950, J. F. Larkins
did execute to Mrs. Nicie M. Bur
gess (Mrs. J. T. Burgess) and N.
M. Gibson, a certain security deed
to certain property described as
follows, to wit:
All that tract or parcel of land
lying and being in the City of Ho
boken, Brantley County, Ga., and
in Land Lots Number Two Hun
dred Twenty-one and Two Hun
dred Forty in the Ninth Land
District of Brantley County,
Georgia, containing Eighteen (18)
acres, more or less, and bounded
as follows; North by lands of
Banner Thomas; East by lands of
Banner Thomas, N. W. Parrish
and a street; South by right of
way of Atlantic Coast Line Rail
road Company, lands of K. S.
Yarn & Co., and lands of J. M.
Jones; and West by lands of K. S.
Varn & Co., and lands of I. J.
Woodard.
ALSO, the following described
tract of land in the City of Hobo
ken, Brantley County, Georgia
described as follows: Beginning
at intersection of State Highway
number Eighty-four and Palm
Avenue, on tthe south side of
Highway number 84 and West
side of Palm Avenue, thence
running West along the South
side of Highway Number 84
a distance of One Hundred
and Fifteen feet; thence
South parallel with Palm Ave
nue a distance of Seventy-five
feet; Thence East parallel with
Highway nurqber 84 a distance of
One Hundred and Fifteen feet to
Palm Avenue; thence North along
the West side of Palm Avenue to
Highway number 84 a distance of
Seventy-five feet, the point of
place of beginning, to secure a
note originally in the principal
sum of $9,000.00 all as shown by
a security deed recorded among
the current public records of said
State and County in Mortgage
Book 29 at pages 266-267, now in
the principal sum of $7,184.34,
besides interest, and Whereas, on
October 3, 1953 the said Mrs. Ni
cie M. Burgess (Mrs. J. T. Bur
gess) and N. M. Gibson conveyed
to the undersigned the said note,
the said security deed and the
said property described therein;
and
WHEREAS, On May 2nd, 1955
J. F. Larkins did execute to the
undersigned an agreement where
by said note and the interest
thereon would become due on
May 2nd, 1956, and said note is
now matured, in default and un
paid, and
WHEREAS, on Oct. 21, 1953 J.
F. Larkins did execute to the un
dersigned a second security deed
on the property herein described
to secure a note for $2016.94;
principal and,
WItEREAS, it was agreed bet
ween J. F. Larkins, and the un
dersigned by the agreement en
tered into on May 2nd 1955, that
said note would become due and
payable on May 2nd, 1956, and
that said note and the interest
thereon is now mature, due and
unpaid, and,
WHEREAS, by said agreement
entered into on May 2nd, 1955,
the said J. F. Larkins became in
debted to the undersigned, in the
further sum of $2080.00 principal
amount, which sum is evidenced
by the promissory note of the
said J. F. Larkins and in favor of
the undersigned, due May 2nd,
1956, it being agreed that said
note was secured by the provis
ions of the two deeds to secure
debt herein mentioned and de
scribed, and
WHEREAS, said note is now
mature, due and in default both
as to principal and interest.
Now, THEREFORE, according
to the original terms of said se
curity deeds and the laws in such
cases made and provided, the un
dersigned will expose for sale to
the highest and best bidder for
cash the above described proper
ty, after proper advertisement,
on the first Tuesday in August
1956, between the legal hours of
sale before the courthouse door
in Nahunta, Brantley County,
Georgia. The proceeds from said
sale will be used to the payment
of said notes, principal, interest
and expenses, and to other in
debtedness of the said J. F. Lar
kins to the undersigned secured
by said security deeds, and the
balance, if any, delivered to the
said J. F. Larkins.
This 11th day of July, 1956.
ROY HARPER
C. Winton Adams, Atty. 8:2
MISTAKES ABOUT
WATERMELONS
W. C. Carter, marketing spec
ialist for the Agricultural Exten
sion Service, says Georgia grow
ers commit three common “sins”
in marketing watermelons. These
are rushing the season with
green or immature melons, in
correct handeling in the field
and in transit, and failure to
grade melons
Brantley Enterprise, Nahunta, Ga., Thursday, July 19, 1956
Deadline for Joining
Soil Bank Plan Nears
ATHENS, Ga. —Georgia cotton, tobacco, peanut and
wheat growers have until July 20 to join the national Acre
age Reserve and share in the some 750 million dollars in
available benefits.
Just how many have or will
sign up for this phase of the new
federal soil bank program is any
body’s guess until the final fig
ures are added up. About the
time the President signed the
new law on May 28, some felt
that Georgia participation would
be slim.
But since details have been
worked out and made public, in
terest appears to have picked up
considerably. One member of the
staff of the state Agricultural and
Conservation Committee co n
cerned with applying the pro
gram noted marked enthusiasm
among some farmers. Others
took a wait-and-see attitude.
AIMED AT CUTTING down
production and price-depressing
surpluses, the acreage reserve
program pays farmers for under
planting their allotments or de
stroying crops already planted.
Payments also are available for
acreage destroyed by floods, hail,
storm or drought.
The benefits are subject to
strict regulations and the stand
ard, of-repeated advice to all
farmers is:
Take no action toward partici
pation in the soil bank until you
have consulted with your , com
munity and county ASC commit
tees.
THE PAYMENTS for all Geor
gia crops except wheat are based
upon per acre yield factors set
up by the committees. Obviously,
an individual farmer’s decision
on participation, especially if it
involves crop destruction, will
hinge largely on the per acre
yield figure alloted to his farm.
The committees have been busy
for some time in developing these
figures. Yield ^factors will be set
up for every eligible farm wheth
er its owner elects to participate
or not.
Except in a few instances
Georgia wheat payments will be
a flat $4 per acrq for allotment
acreage not planted last fall be
cause of adverse weather. A lim
ited number of growers are re
ported to be seeking benefits on
the basis of the national average
rate of $1.20 by plowing up or
otherwise destroying acreage.
TIME LIMITS for plowing up,
mowing and otherwise destroying
acreage of all crops have been
set by the Georgia ASC commit
tee. The date was July 15 for
tobacco and wheat and is July 31
for cotton and peanuts.
The unit payment rates for the
main Georgia crops are 18 cents
a pound for flue-cured tobacco
15 cents a pound for cotton and
GEORGIA, BRANTLEY
COUNTY..
Whereas, Mrs. Mellisa Shuman,
administratrax of the estate of
the late A. J. B. SHUMAN, has
filed her petition for discharge as
such administratrix, as provided
by Chap. 113, section 2301, of the
current Code of this State. All
persons concerned are required to
show cause before me at the Aug.
term, 1956 of my Court v^hy such
discharge should not be granted.
This the 2nd day of July, 1956.
Claude A. Smith
Ordinary, Brantley Co. Ga.
C. Winton Adams,
8 2.
Atty, for petitioner.
Charles Batten
Vs.
Tiney E. Batten
SUIT FOR DIVORCE, in
Brantley Superior Court.
TO TINEY E. BATTEN, De
fendant..
You are hereby commanded to
appear at the Sept, term, 1956,
to answer in said matter.
Witness the Hon. Cecil Rod
denberry, Judge, of said Court.
This the 2nd day of July, 1956.
D. F. Herrin, Clerk
Brantley Co. Ga. Superior
Court.
C. Winton Adams,
Plaintiff’s Attorney
7:5-12 & 8:2-9
COWS LIKE IT COOL
Well-fed dairy cows can stand
a lot of cold weaker, but Exten
sion Service Dairyman Frank
Fitch says they react in a hurry
when it gets hot. The result is a
drop in feed consumption and
milk production. Fitch urged
dairy farmers to do whatever
they can to make their cows com
fortable during the hot days
ahead.
Watch the label on your
paper, it indicates the date
your subscription will ex
pire.
3 cents for peanuts.
The determined yield of tobac
co for any farm cannot exceed
115 per cent of the national av
erage of 1,419 pounds an acre.
Hence, the maximum payment
for any single acre removed from
production is $293.
NEITHER TOBACCO nor cot
ton grade is considered in de
termining acreage yields for a
farm. Hence, the program is re
garded as having an especially
healthly effect on the crop supply
and surplus situation by en
couraging the removal of poor
grades from the harvest.
To help arrive at acre-yield
figures for individual farms
check yields based on county
wide averages are assigned to
the counties. The composite of
the established yields for the
farms for compliance purpose
must be in line with this county
average.
DEWEY HAYES
For Solicitor
General
To the People of the
Waycross Judicial Circuit;
I wish to announce my candid
acy for Solicitor General of the
Waycross Judicial Circuit in the
September 12, primary, 1956.
I am a full-time Democrat and
will abide by the rules of the
Democratic Party set up to go
vern the primary.
I am seeking election as your
Solicitor General on the basis of
my past record, my legal exper
ience, and desire tp ably repre
sent you, the people of this Judi
cial Circuit. It is my purpose to
represent all the people in a fair
and consciencious manner at all
times. I will prosecute the guilty
to the’fullest extent of the law
and protect the inocent in the
same manner. My desire will be
to truly make the courthouse a
Hall of Justice
I will make an immediate in
vestigation on all alleged crimes
and institute a pre-trial confer
ence with all court officials on
the week prior to opening of
court. The purpose for this will
be to speed up the court and
have all cases ready for trial.
This will insure justice and will
greatly aid the efficient opera
tion of court.
Your support and influence on
my behalf will be greatly ap
preciated.
Respectfully,
DEWEY HAYES. ts
Thi« man can give you
lependable
delivery of
THE
CHRISTIAN
SCIENCE
MONITOR
Housewives, businessmen,
teachers, and students all over
the world read and enjoy this
international newspaper, pub
lished daily in Boston. World
famous for constructive news
stories and penetrating editorials.
Special features for the whole
family.
The Christian Science Monitor
One Norway St., Boston IS, Moss.
Send your newspaper for the time
checked. Enclosed find my check o'
money order.
I year sl6 □ 6 months $8 □
3 months $4 □
Nome ”*
* Address ——
* City Zone ‘ State "
» ,
Intmatlonal
daily
